TERMS
OF SERVICE.
Last updated: September 21, 2026. These terms govern use of our website and services. Project-specific agreements apply where stated.
Agreement to terms
By accessing or using the BengalTech Solutions website and services, you agree to be bound by these Terms of Service. If you disagree with any part of these terms, you may not access our services.
Services
BengalTech Solutions provides web development and app development services, including but not limited to:
- ->Website design and development
- ->Mobile app development
- ->E-commerce solutions
- ->Web application development
- ->Maintenance and support services
Project agreements
All projects are subject to a separate written agreement that outlines specific terms, deliverables, timelines, and pricing. These Terms of Service apply in addition to any project-specific agreements.
Payment terms
Payment schedule
Payment terms will be specified in individual project agreements. Typically:
- 50% payment required upfront to begin work
- 50% payment upon project completion
- For larger projects, milestone-based payments may be arranged
Payment methods
We accept the following payment methods:
- bKash
- Nagad
- Bank transfer
- PayPal
Late payments
Payments are due as specified in the project agreement. Late payments may result in project delays or suspension of services.
Client responsibilities
Clients are responsible for:
- Providing accurate and complete information
- Providing content, images, and materials in a timely manner
- Reviewing and approving work at each milestone
- Making payments according to the agreed schedule
- Providing feedback and decisions in a timely manner
Intellectual property
Client content
Clients retain ownership of all content, images, and materials they provide to us.
Deliverables
Upon full payment, clients receive ownership of the final deliverables as specified in the project agreement. Source code and design files will be provided upon request after project completion.
Revisions and changes
Each project includes a specified number of revision rounds as outlined in the project agreement. Additional revisions may incur additional charges. Significant changes to project scope may require a new agreement and additional fees.
Timelines
Project timelines are estimates based on the information provided. Delays caused by client feedback, content delays, or scope changes may extend the timeline. We will communicate any timeline changes promptly.
Warranties and guarantees
We guarantee that:
- Work will be performed in a professional manner
- Deliverables will be free from defects for the support period specified
- We will fix any bugs or errors during the support period
We do not guarantee specific business results, website traffic, or conversion rates.
Limitation of liability
BengalTech Solutions shall not be liable for any indirect, incidental, special, or consequential damages arising from the use of our services. Our total liability shall not exceed the total amount paid by the client for the specific project.
Cancellation and refunds
If a project is cancelled:
- Work completed up to the cancellation point will be billed
- No refunds will be provided for work already completed
- Any materials or deliverables created will be provided to the client
Confidentiality
We respect the confidentiality of client information and project details. We will not disclose client information to third parties without consent, except as required by law.
Changes to terms
We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting on this page. Continued use of our services after changes constitutes acceptance of the new terms.
Governing law
These Terms of Service shall be governed by and construed in accordance with the laws of Bangladesh. Any disputes shall be resolved through mutual discussion, and if necessary, through the courts of Bangladesh.
Contact
For questions about these Terms of Service: